Chapter 853. for the relief of Nathaniel McKay and the executors of Donald McKay
465 words·~2 min read·
/statutes-at-large/vol-26/chapter-853-5173986·A research copy — for the controlling text, always check the official state or federal source. Not legal advice.
CHAP. 853.— An Act for the relief of Nathaniel McKay and the executors of Donald McKay.August 30, 1890. *Be it enacted by the Senate and House of Representatives of the United States of America in Congress assembled*,Nathaniel McKay and executors of Donald McKay. That the claims of Nathaniel McKay and the executors of Donald McKay for further compensation for the construction of the iron-clad monitors Squando and Nauset, and the side-wheel steamer Ashuelot, may be submittedClaim referred to Court of Claims. by said claimants within six months after the passage of this act to the Court of Claims, under and in compliance with the rules and regulations of said court; and said court shall have jurisdiction to hear and determine and render judgment upon the same: *Provided, however*,*Provisos*.
That the investigation of said claim shall be made upon the following basis: The said court shall ascertain the additional costBasis of examination. which was necessarily incurred by the contractors for building the light-draught monitors Squando and Nauset and the side-wheel steamer Ashuelot in the completion of the same, by reason of any changes or alterations in the plans and specifications required, and delays in the prosecution of the work: *Provided*, That such additionalAdditional cost from changes, etc. cost in completing the same, and such changes or alterations in the plans and specifications required, and delays in the prosecution of the work were occasioned by the Government of the United States; but no allowance for any advance in the price of labor or material shall be considered unless such advance occurred during the prolonged term for completing the work rendered necessary by delay resulting from the action of the Government aforesaid, and then only when such advance could not have been avoided by the exercise of ordinary prudence and diligence on the part of the contractors: *And provided further*, That the compensation fixed by the contractors and the Government for specific alterations in advance of suchAlterations agreed upon in advance. alterations shall be conclusive as to the compensation to be made therefor: *Provided.* That such alterations, when made, complied withAlterations complying with specifications. the specifications of the same as furnished by the Government aforesaid: *And provided further*, That all moneys paid to said contractors by the Government over and above the original contract price forDeductions for payments. building said vessel shall be deducted from any amounts allowed by said court by reason of the matters hereinbefore stated: *And provided further*, That if any such changes caused less work and expensesDeductions for altercations decreasing expense, etc. to the contractors than the original plan and specifications a corresponding deduction shall be made from the contract price, and the amount thereof be deducted from any allowance which may be made by said court to said claimants.
Approved, August 30, 1890.