Sec. 130. no bonuses for contractors behind schedule or over budget

1,116 words·~5 min read·/statute-compilations/comps-15716/sec-130

A research copy — for the controlling text, always check the official state or federal source. Not legal advice.

## SEC. 130 no bonuses for contractors behind schedule or over budget None of the funds made available in this Act for the Architect of the Capitol may be used to make incentive or award payments to contractors for work on contracts or programs for which the contractor is behind schedule or over budget, unless the Architect of the Capitol, or agency-employed designee, determines that any such deviations are due to unforeseeable events, government-driven scope changes, or are not significant within the overall scope of the project and/or program. ## LIBRARY OF CONGRESS ### Salaries and Expenses For all necessary expenses of the Library of Congress not otherwise provided for, including development and maintenance of the Library’s catalogs; custody and custodial care of the Library buildings; information technology services provided centrally; special clothing; cleaning, laundering and repair of uniforms; preservation of motion pictures in the custody of the Library; operation and maintenance of the American Folklife Center in the Library; preparation and distribution of catalog records and other publications of the Library; hire or purchase of one passenger motor vehicle; and expenses of the Library of Congress Trust Fund Board not properly chargeable to the income of any trust fund held by the Board, $510,164,000, of which not more than $6,000,000 shall be derived from collections credited to this appropriation during fiscal year 2020, and shall remain available until expended, under the Act of June 28, 1902 (chapter 1301; 32 Stat. 480; 2 U.S.C. 150): *Provided*, That the Library of Congress may not obligate or expend any funds derived from collections under the Act of June 28, 1902, in excess of the amount authorized for obligation or expenditure in appropriations Acts: *Provided further*, That the total amount available for obligation shall be reduced by the amount by which collections are less than $6,000,000: *Provided further*, That of the total amount appropriated, not more than $18,000 may be expended, on the certification of the Librarian of Congress, in connection with official representation and reception expenses, including for the Overseas Field Offices: *Provided further*, That of the total amount appropriated, $9,110,000 shall remain available until expended for the digital collections and educational curricula program: *Provided further*, That of the total amount appropriated, $1,350,000 shall remain available until expended for upgrade of the Legislative Branch Financial Management System: *Provided further, *That of the total amount appropriated, $250,000 shall remain available until expended for the Surplus Books Program to promote the program and facilitate a greater number of donations to eligible entities across the United States: *Provided further,* That of the total amount appropriated, $3,587,000 shall remain available until expended for the Veterans History Project to continue digitization efforts of already collected materials, reach a greater number of veterans to record their stories, and promote public access to the Project: *Provided further*, That of the total amount appropriated, $10,000,000 shall remain available until expended for the development of the Library’s Visitor Experience project, and may be obligated and expended only upon approval by the Subcommittee on the Legislative Branch of the Committee on Appropriations of the House of Representatives and by the Subcommittee on the Legislative Branch of the Committee on Appropriations of the Senate. ### Copyright Office ### salaries and expenses For all necessary expenses of the Copyright Office, $91,840,000, of which not more than $43,221,000, to remain available until expended, shall be derived from collections credited to this appropriation during fiscal year 2020 under sections 708(d) and 1316 of title 17, United States Code: *Provided*, That the Copyright Office may not obligate or expend any funds derived from collections under such section in excess of the amount authorized for obligation or expenditure in appropriations Acts: *Provided further*, That not more than $6,482,000 shall be derived from collections during fiscal year 2020 under sections 111(d)(2), 119(b)(3), 803(e), and 1005 of such title: *Provided further*, That the total amount available for obligation shall be reduced by the amount by which collections are less than $49,703,000: *Provided further*, That of the funds provided under this heading, not less than $17,100,000 is for modernization initiatives, of which $10,000,000 shall remain available until September 30, 2021: *Provided further*, That not more than $100,000 of the amount appropriated is available for the maintenance of an “International Copyright Institute” in the Copyright Office of the Library of Congress for the purpose of training nationals of developing countries in intellectual property laws and policies: *Provided further*, That not more than $6,500 may be expended, on the certification of the Librarian of Congress, in connection with official representation and reception expenses for activities of the International Copyright Institute and for copyright delegations, visitors, and seminars: *Provided further*, That, notwithstanding any provision of chapter 8 of title 17, United States Code, any amounts made available under this heading which are attributable to royalty fees and payments received by the Copyright Office pursuant to sections 111, 119, and chapter 10 of such title may be used for the costs incurred in the administration of the Copyright Royalty Judges program, with the exception of the costs of salaries and benefits for the Copyright Royalty Judges and staff under section 802(e). ### Congressional Research Service ### salaries and expenses For all necessary expenses to carry out the provisions of section 203 of the Legislative Reorganization Act of 1946 (2 U.S.C. 166) and to revise and extend the Annotated Constitution of the United States of America, $120,495,000: *Provided*, That no part of such amount may be used to pay any salary or expense in connection with any publication, or preparation of material therefor (except the Digest of Public General Bills), to be issued by the Library of Congress unless such publication has obtained prior approval of either the Committee on House Administration of the House of Representatives or the Committee on Rules and Administration of the Senate: *Provided further*, That this prohibition does not apply to publication of non-confidential Congressional Research Service

(CRS)products: *Provided further*, That a non-confidential CRS product includes any written product containing research or analysis that is currently available for general congressional access on the CRS Congressional Intranet, or that would be made available on the CRS Congressional Intranet in the normal course of business and does not include material prepared in response to Congressional requests for confidential analysis or research. ### National Library Service for the Blind and Print Disabled ### salaries and expenses For all necessary expenses to carry out the Act of March 3, 1931 (chapter 400; 46 Stat. 1487; 2 U.S.C. 135a), $58,563,000: *Provided*, That of the total amount appropriated, $650,000 shall be available to contract to provide newspapers to blind and physically handicapped residents at no cost to the individual. ## Administrative Provision

Connectionstraces to 4

Traces to 4 documents

U.S. Code

statutes-at-large